Terms of Use

Welcome to www.sabiosphere.in (the “Site”), operated by SabioSphere Studios LLP (“we”, “us”, or “our”). By accessing or using our Site or services, you agree to be bound by these Terms of Use (“Terms”). If you do not agree to these Terms, please refrain from using the Site.

1. Acceptance of Terms

By visiting or using this Site, you agree to comply with and be legally bound by these Terms. These Terms govern your access to and use of the Site, as well as any information, text, graphics, photos, or other materials provided.

2. Services

SabioSphere Studios LLP offers the following services, including but not limited to:

• Interior design and architectural consultations
• 2D layouts and 3D renderings
• Turnkey project management and on-site execution
• Custom furniture and decor curation

All services are subject to project-specific agreements, which outline deliverables, timelines, and commercial terms.

3. Permitted Use of Site

You may access this Site solely for personal, non-commercial purposes such as:

• Viewing our portfolio and service offerings
• Learning about our design philosophy
• Submitting inquiries via the contact form

Any misuse, including unauthorized copying, scraping, or reverse engineering of the Site or its content, is strictly prohibited.

4. User Responsibilities

By using the Site and engaging with us, you agree to:

• Provide accurate, complete, and up-to-date information in all forms and communications
• Cooperate during site visits, surveys, design reviews, and installations
• Respond to emails or messages promptly to avoid project delays
• Accept responsibility for approvals, timelines, and coordination as agreed in project documentation

5. User Data and Privacy

When you submit your personal data through our Site, you agree to its collection, storage, and use as outlined in our Privacy Policy. We value your privacy and are committed to protecting it.

6. Intellectual Property

• All designs, drawings, renderings, images, and other deliverables shared by us are the intellectual property of SabioSphere Studios LLP unless otherwise agreed in writing.
• Upon full payment, you are granted a non-exclusive, non-transferable license to use the deliverables for the specific project only.
• You may not reproduce, distribute, modify, or use our materials for commercial or unrelated projects without prior written consent.

7. Payment Terms

• Fees: Project fees are defined on a case-by-case basis and shared with you before project initiation.
• Milestones: Payment schedules and milestones will be clearly specified in the signed project agreement.
• Refunds & Cancellations: These are governed strictly by the terms in your individual project contract.

8. Vendor & Third-Party Liability

We may recommend or coordinate with external contractors, vendors, or product suppliers. These parties operate independently, and we assume no liability for their actions, performance, warranties, or services.

9. Limitation of Liability

• We are not liable for any indirect, incidental, or consequential damages arising from your use of the Site or our services.
• Our total liability, if any, shall not exceed the amount you paid us for the relevant project.

10. Force Majeure

Neither party shall be held responsible for delays or failure in performance due to unforeseen circumstances beyond their reasonable control, including but not limited to natural disasters, strikes, labor shortages, pandemics, or government restrictions.

11. Indemnification

You agree to indemnify, defend, and hold harmless SabioSphere Studios LLP, its team, and affiliates from any claims, liabilities, damages, or expenses resulting from your breach of these Terms or misuse of our content or services.

12. Termination

• We reserve the right to terminate or suspend services immediately upon breach of these Terms or failure to fulfill contractual obligations.
• Upon termination, all unpaid dues become payable, and you must discontinue the use of any proprietary materials or designs shared with you.

13. Governing Law and Dispute Resolution

These Terms are governed by the laws of India. Any disputes arising from the use of this Site or our services will be subject to the exclusive jurisdiction of the courts in Kolkata, India.

14. Disclaimer

All content on this Site is for informational purposes only and does not constitute legal, design, or financial advice unless explicitly stated in a written project contract. We reserve the right to modify or discontinue any aspect of the Site or services without prior notice.

15. Changes to Terms

We may revise these Terms from time to time. Any material changes will be communicated via email or by posting a notice on this Site. Continued use of the Site after such changes constitutes acceptance of the updated Terms.

16. Contact Information

For any questions or concerns regarding these Terms, please contact us at: